You may cancel this contract from the day you enter into the contract until 10 days after you receive a copy of the contract. You do not need a reason to cancel. If you do not receive the goods or services within 90 days of the date stated in the contract, you may cancel this contract within one year of the contract date. You lose that right if you accept delivery after the 30 days. There are other grounds for extended cancelation. For more information, you may contact your provincial/territorial consumer affairs office. If you cancel this contract, the seller has 15 days to refund your money and any trade-in, or the cash value of the trade-in. You must then return the goods. To cancel, you must give notice of cancelation at the address in this contract. You must give notice of cancelation by a method that will allow you to prove that you gave notice, including registered mail, fax or by personal delivery.
You acknowledge you have the legal capacity to enter into this agreement and that its terms and conditions are subject to review and approval by Budget Blinds, Division to JE Design & Décor Ltd, who may cancel this agreement refunding any down payment. Budget Blinds reserves the right to cancel the agreement should Budget blinds experience unforeseen circumstances that result in additional supply costs, including increases in materials, gasoline, transportation or labour costs. Further, Budget Blinds reserves the right to withdraw from the agreement in whole or in part if safe access to any part of the structure or land is not possible using equipment normally employed by Budget Blinds. In the event the work cannot be performed in accordance with local codes or ordinances, any payment for merchandise and/or labour made hereunder shall be refunded, and this agreement shall be null and void and of no effect.
You agree to pay to Budget Blinds the amount specified herein which will cover the price of said merchandise and the installation. This agreement, including the specification, may not be altered or modified except by written agreement between the parties hereto and oral understanding and agreements shall not be binding unless set forth herein. Any changes made by you in these specifications necessitating additional, merchandise or labour shall not be included or covered by this agreement but shall be provided for under separate and additional orders from you via a written change order. In the event a condition arises that Budget Blinds was not aware of at the time it made it visual inspection of your Premises, Budget Blinds reserves the right to adjust its price in order to reasonably perform its work in accordance with the plans and specifications. Such adjustments shall be fully discussed with you and shall not include those conditions that should have been deleted upon a reasonable substantially completed within 90 days hereafter unless a different estimate completion date is shown herein. You understand this is only an estimated date and you will be contacted prior to this date to schedule the actual installation date. Failure by Budget Blinds without lawful excuse to substantially commence work within 20 days from the approximate date shown on the reverse is a violation of the Contractors License Law.
You represent that any information or measurement that you have provided to Budget Blinds are complete and correct to the best of your knowledge. You understand that an additional installation fee may be required if any of this information is not correct. Any changes the installation that may occur as a result of incomplete or incorrect information you have provided to Budget Blinds.
You warrant that you are the owner of the property on which the work is to be performed or that you are otherwise authorized on behalf of the owner(s) to enter into this Agreement and you have adequate homeowner's insurance to cover and compensate for any loss caused by theft of the Products, accidents, or malicious or negligent damage while the Products are on the premises. You further warrant that you will assure the safety of all Product and Materials left at your premise to Budget Blinds and their servants and workmen at all reasonable times so that Budget Blinds may complete the installation in accordance with this agreement. Budget Blinds shall perform its work in a timely fashion subject to the delivery of the Product and Materials to the premises and reasonable access given to Budget Blinds and its subcontractors to your premises. In any event, Budget Blinds will not be liable to you for any delay and you shall not claim against Budget Blinds for any inconvenience resulting from such a delay. You agree to allow the free use of any services and utilities in a reasonable amount, supplied to the property for carrying out the installation. You agree to pay Budget Blinds the reasonable cost of enforcement for collection if it is necessary for Budget Blinds to retain an attorney and/or to initiate legal proceedings if instigated, in addition to other sums, as permitted by provincial law. Budget Blinds shall take title to any merchandise ordered and Customer shall be at the full risk of loss. However, until Budget Blinds has been paid in full for all services due for any unpaid amounts under any sales order or under the Agreement, it shall retain a first security interest in the merchandise in the amount of any unpaid balance plus attorney's fees and cost of collection. Budget Blinds shall not be required to relinquish possession of the merchandise ordered until its security interest has been paid in full. Customer hereby authorizes Budget Blinds to record its security interest.
You certify that the product information described on the face of this order is accurate and complete. You understand that the purchase price of the product payable to Budget Blinds in full at the time of ordering and is not refundable. You also understand the products described are specifically designed and custom-built and that Budget Blinds will take action upon execution of this agreement to order and have constructed those items set forth herein. Therefore, this agreement is not subject to cancelation for any reason after 10 days of order placement. The Buyer's Right to Cancel takes precedence. The delivery date, when given, shall be deemed approximate and performance is subject to delays caused by strikes, fires, acts of God or other reasons not under the control of Budget Blinds, as well as the availability of the product, or a component product at the time of delivery. You understand that Budget Blinds will have no obligation for the installation of the product unless specifically arranged for by an installation contract with Budget Blinds except as found in any applicable manufacturer's warranty, Budget Blinds makes no warranty expressed or implied, regarding the products or the components and hereby claims all warranty or stated or implied fitness for a particular purpose and Budget Blinds shall have liability for direct, indirect, special, consequential, incidental or punitive damages. Binding Arbitration of Disputes: Any disputes or claim in law or equity, litigation, suit, action, or otherwise ("Claim") between or involving Budget Blinds, JE Design & Decor Ltd (and/or including any claim lodged against any of their officers, directors, accountants, attorneys, employees, sales representative, and any other related persons or entities), whether concerning, relating or arising out of the agreement or any other document, any breach of any duty, any cause of action for recession or setting aside agreement of sale, any claims of fraud or misrepresentation and whatever claims, causes of action, shall be decided by mutual binding arbitration and not by court action except for judicial review or arbitration proceeding and judicial small claims proceeding with a jurisdictional maximum limit of $5000. The parties expressly agree that any claim or dispute in excess of $5000 shall be decided only by mutually binding arbitration. The parties hereto specifically agree that the arbitration shall take place at an appointed time and place in the country in which the sale was made. It is expressly agreed by the parties that the prevailing party in any such arbitration or award of the arbitration shall be binding and shall be entered in a court of competent jurisdiction. Customer agrees to waive any right to seek or recover upon any claims for punitive, exemplary, incidental, consequential, lost income, profits and similar damages due to any theory of law or cause of action. Customer agrees that he/she or they shall be limited to the recovery of out-of-pocket losses actually sustained as the date of the arbitration award.
*2.4% on all credit card transactions will apply to any canceled order(s)